compose.kerala.gov.in

egazette.kerala.gov.in

printing.kerala.gov.in

േകരള സരകാര

GOVERNMENT OF KERALA

േകരള ഗസറ്

KERALA GAZETTE

ആധികാരികമായി ്പസിദെപടുതുനത

PUBLISHED BY AUTHORITY

Regn.No. KERBIL/2012/45073

dated 2012-09-05 with RNI

Reg No.KL/TV(N)/634/2021-2023

വാല്ം 15

Vol. XV

നമര

No.

െചാവ, 2026 െസപറംബര 08

Tuesday, 08th September 2026

1202 ചിങം 23

23rd Chingam 1202

1948 ഭാ്ദം 17

17th Bhadra 1948

Part IV

Miscellaneous Notifications

േകരള സരകാര

GOVERNMENT OF KERALA

2026

This is a digitally signed Gazette.

Authenticity may be verified through https://compose.kerala.gov.in/

കേരള കേറ്റ് ഇലക്ട്രിസിറ്റി ക ോര്‍ഡ് ലിറിറ്റഡ്

അറിയിപ്പ്

നമ്പര്‍. ഡി. ി-ഗസറ്റ്/2026-27/280 തീയതി : 18.08.2026

(ഇന്ത്യന് ഇലക്ട്രിസിറ്റി ആക്ട് 2003 ലല 164 ലസക്ഷന് 185(2) (a)(b) വകുപ്പ് പ്രേോരം

ല ോതുജനങ്ങളുലെ അറിവികലക്കോയി രസയലപ്പടുത്തുന്നത്)

കേരള സംസ്ഥോനത്തിലല വര്‍ധിച്ചു വരു വന ന്ന യവതി ഉതി ഗ കയോഗത്തിന്

രിഹോരറോയി, ആലപ്പുഴ ജില്ലയിലല നിലവിലുള്ള 66 ലേ വി യലന് പുനന ധോരണ

പ്രവര്‍ത്തനങ്ങക്ക്കോയി

ലേ.ഇസ്.ഇ. ി.

ലിറിറ്റഡിലല

ഗകതി യോഗസ്ഥകരോ

അവര്‍

ചുറതലലപ്പടുത്തുന്ന ററ്റു വയക്തിേകളോ ജില്ലയിലല തോലഴ ലേോടുത്തിരിക്കുന്ന സ്ഥലങ്ങളില്

110 ലേ.വി ഡ ിക് സര്‍േൂട്ട് ് യലന് േെന്നുക ോേോന് ഗകേശിക്കുന്ന സവേോരയ ഭൂറിേക്

ഗക് ലപ്പലെയുള്ള നിലവിലല 66 ലേ വി േെന്നുക ോകുന്ന വസ്തുക്കളില് കൂെി അവന ലെ

നിയറോനുസൃതറോയ കൃതയനിര്‍ വഹണത്തിലെ ഭോഗറോയി നിശ്ചിത സറയങ്ങളില്

പ്രകവശിക്കുന്നതോലണന്നുള്ള വിവരം ന്ധലപ്പട്ട് ഇല്ലോവലരയും ഇതിനോല് അറിയിച്ചു വരു

ലേോള്ളുന്നു. പ്രസ്തുത കജോലിേക് ലെയ്യുന്നതില് നിന്നും അവലര തെസ്സലപ്പടുത്തുന്നത്

നിയറ വിന ധറോലണന്നും അറിയിക്കുന്നു.

നം.

കജോലിേക്

സ്ഥലം

പുന്നപ്ര-ആലപ്പുഴ യലന്

- 8.693 േി.റി.

അമ്പലപ്പുഴ തോലൂക്കിലല പുന്നപ്ര, റവൂര്‍, ആലപ്പുഴ

ലവേ്, ആരയോെ് സൗത്ത് ഇന്നി വികല്ലജുേക്

പുന്നപ്ര-റോകവലിക്കര

യലന് - 33.24 േി.റി.

റോകവലിക്കര തോലൂക്കിലല റോകവലിക്കര, േണ്ണറങ്കലം

ഇന്നീ വികല്ലജുേക്

േോര്‍ ത്തിേപ്പള്ളി തോലൂക്കിലല കെപ്പോെ്, െികങ്ങോലി,

േോര്‍ത്തിേപ്പള്ളി, ഹരിപ്പോെ്, കുറോരപുരം, േന വോറ്റ

ഇന്നീ വികല്ലജുേക് .

ള്ളം-കുട്ട് നോെ് യലന്

- 18 േി.റി

കേോട്ട് യം തോലൂക്കിലല നച്ചിക്കോെ്, നോട്ട് േം, തിന വോര്‍പ്പ്

ഇന്നീ വികല്ലജുേക്

ആലപ്പുഴ –

ോതിരോപ്പള്ളി യലന് -

6.30 േി.റി

അമ്പലപ്പുഴ തോലൂക്കിലല പുന്നപ്ര, റവൂര്‍, ആലപ്പുഴ

ലവേ്, ആരയോെ് സൗത്ത് ഇന്നീ വികല്ലജുേക്

റോകവലിക്കര-െക്കുവള്ളി

യലന് - 18 േി.റി

റോകവലിക്കര തോലൂക്കിലല റോകവലിക്കര വികല്ലജ്

കുന്നത്തൂര്‍ തോലൂക്കിലല ലതകക്കക്കര, ചുനക്കര,

തോറരക്കുളം വികല്ലജുേക്

റോകവലിക്കര മുനിസിപ്പോലിറ്റിയിലല ക ോന വഴി, ശൂരനോെ്

കനോര്‍ത്ത് വികല്ലജുേക്

ഒപ്പ് /-

ലഡ ൂട്ട് ി െീഫ് ഇന് ജിനീയര്‍

ട്രോന് സ്മിഷന് സര്‍ ക്കിക് , ആലപ്പുഴ

08th September 2026

KERALA GAZETTE

____________________________________________________________________________________________________________________________

This is a digitally signed Gazette.

Authenticity may be verified through https://compose.kerala.gov.in/

In the Court of The Additional Sub Judge, Kottayam

Present : SMT. SONY, A. S., Additional Sub Judge (In-Charge)

Monday the 6th day of April, 2026/16th day of Chaitra, 1948.

I.A. 05/2026 in OP (Insolvency) 04/2018

Petitioner :-

ADV. P. K. VINODKUMAR,

Special Receiver.

Counter Petitioners :-

1. K.V. Viswanathan (Died), aged 68 years, S/o. Vasudeva Panikkar, residing at

Kunnathukalathil Jino Bhavan, Thekkumgopuram, Thirunakkara Kara, Kottayam P.O.,

Kottayam Village, Kottayam Taluk, Kottayam District-686 001.

2. Ramani Viswanathan, aged 74 years, W/o. K.V. Viswanathan, residing at

Kunnathukalathil Jino Bhavan, Thekkumgopuram, Thirunakkara Kara, Kottayam P.O.,

Kottayam Village, Kottayam Taluk, Kottayam District-686 001.

CP 1 Died

CP 2 By Adv. K. C. Eldho, Adv. Jijo Thomas, Adv. Mallenathan M., Adv. Anitha V. R. &

Adv. Aneesh James.

This petition coming up for consideration on 6-4-2026 and court on the same day passed the

following.

ORDER

Petition allowed. Produce Gazette notification and paper publication published in the leading

newspaper 19-5-2026.

Pronounced in open court on this the 6th day of April, 2026.

SONY, A. S.,

Additional Sub Judge

(In-charge).

APPENDIX:- Nil

(Id.)

Additional Sub Judge.

(Sd.)

AMRITHA, T.,

Additional Sub Judge.

For SONY, A. S.,

Additional Sub Judge

(In-charge).

KERALA GAZETTE

Part IV

____________________________________________________________________________________________________________________________

This is a digitally signed Gazette.

Authenticity may be verified through https://compose.kerala.gov.in/

IN THE COURT OF THE HONOURABLE ADDITIONAL SUB COURT, KOTTAYAM

Insolvency Petition No. 4 of 2018

Petitioners/Debtors

Respondents

1. K.V. Viswanathan

NJT Finance Pvt. Limited & others

Kunnathukalathil

2. Ramani Viswanathan

do.

NOTICE (FORM NO.12)

Issued under section 31 & Rule XXI of the Kerala Insolvency Act 1955.

The petitioners herein submitted the above numbered Insolvency Petition for adjudging them as

Insolvents before this court on 19-6-2018. In the above case the petitioners were adjudged as Insolvents

on 12-3-2026. By the order the Insolvents are directed to apply for discharge within 6 months.

The creditors are directed to submit the claim petitions in Form No. 5 of the Kerala Insolvency Rules with

the supporting documents in original.

(Sd.)

Sub Judge

Kottayam,

Addl. Sub Court (Insolvency Court),

4-4-2026.

Kottayam.

08th September 2026

KERALA GAZETTE

____________________________________________________________________________________________________________________________

This is a digitally signed Gazette.

Authenticity may be verified through https://compose.kerala.gov.in/

 

IP 5/2024.

:— , , !"#

$ %&' ( ") *+ "

,- ./0:— 12345 4%5 *+6 67, 8 .-

9 +#: 8 # 7 4

: ./0:— ,; 4%5 *+6 67, + < .-

9 +#: 8 # 7 4

- ./0:— , 4 = >, *= ? +.,.

,- ./0 5A OS 990/2012˛mw

5 ( *+ , : ./0 5A

OS 185/2011˛mw 5 ( *+ - ./0

%' 5B%5 1 46 PLP 350/2016˛mw 1 7

-C

5D)

-C 5 #"2 # '

E *+D) +$ - ") & 85 F 5 G;

10-˛mw - *+ = (H 15-9-2025 % 1!H

85 F I *+D) +H&C $- 8 ' 14 -.

J# *+ ,

. . 5K 2L*M= =

G. *+" N,

K 17365.

KERALA GAZETTE

Part IV

____________________________________________________________________________________________________________________________

This is a digitally signed Gazette.

Authenticity may be verified through https://compose.kerala.gov.in/

Page 1 of 5

KERALA BOOKS AND PUBLICATIONS SOCIETY,

KAKKANAD, KOCHI – 682030

GST No. 32AAATK2642L1ZR

e-Tender Notice for the Operating charges (click charges) for the Online bar code / QR code /

variable data printing system attached with our GossWS – D 598web offset printing machine

No. P1-3488/2026/3510

Date: 24.08.2026

e–Tender notice

e- tenders are invited through www.etenders.kerala.gov.infor fixing the operating charges (click

charges) for printing of variable data barcoding with QR code, for the high speed online

barcoding unit [Model: VIS1200 (K600i)] which is attached to the Goss WS – D 598high

speed web offset printing machine with the detailed technical specificationand terms and

conditions attached.

Technical specification of work to be executed:

1. Print Head details : Kodak “Pros – S (10) series – Jetting module – 4.2”

2. Print width : 782mm (4.25" upto 30.8")

2. Our sheet size 600 x760 mm with 30 ups

3. One up dimension

a. Small size - 193 x 70 mm

b. Big size- 250 x 80 mm

4. Quantity: 180 -200crores per annum

5. Image Resolution: 600 x 600 dpi

6. Dimensions of variable data in a single label

15 x 15 mm (QR code)

ii.

8 x 28 mm (Barcode)

iii.

7 x 38 mm (Alpha numeric variable data)

iv.

3 x 20 mm (Alpha numeric variable data)

4 x 27 mm (Alpha numeric variable data)

vi.

3 x 40 mm (Alpha numeric variable data)

vii.

18 mm width x 3mm height (Alpha numeric variable data)

viii.

12 mm width x 2mm height (Alpha numeric variable data) - 3nos.

(The dimensions and the number of variable data may change from time to time)

7. Speed

Our GossWS – D 598web offset printing machine operating speed: 25,000 - 30,000 IPH

a. The variable data is to be printed on sheets of range 50-90 gsm paper

b. The data printed on the tickets should be 100% dried and scratch proof.

c. The barcodes and QR codes printed by the variable data printed on tickets

must be 100% scannable at high speeds.

Terms and Conditions

1. All

tenders/bid

shall

accepted

only

through

online

mode

(https://

etenders.kerala.gov.in) and no manual submission of the same shall be allowed.

08th September 2026

KERALA GAZETTE

____________________________________________________________________________________________________________________________

This is a digitally signed Gazette.

Authenticity may be verified through https://compose.kerala.gov.in/

Page 2 of 5

2. EMD for Rs. 15,00,000/- should be remitted through online, as per the terms and

conditions of the e-tender site. The benefits will be limited only to the MSMEs which are

working within the state of Kerala (G.O (P) no. 10/2023/SPD dated 11.12.2023)

3. Re - submission of offer is possible, before the last date as permitted in the site.

4. Offers are acceptable only up to 11.00 am on 16.09.2026

5. Opening of bid is scheduled at 11.30 am on 17.09.2026

6. Prices should be quoted F.O.R KBPS, Kakkanad, Ernakulam, Kerala

7. The offer should be valid up to one yearfrom the date of opening of the tender.

8. The contract will be for a period of one (1) year from the date of signing, but the

Management reserves the right to shorten/ extend the contract at the same rate quoted in

this e- tender.

9. The successful party/contractor should provide manpower, all consumables including

print heads, pigment based ink (which is tamper free and resistant to water/chemical) for

running the system.

10. The successful party/contractor should provide computer, printer and manpower for

carrying out the corrections in labels as per the requirement of KBPS.

11. The rate should be inclusive of printing of barcodes with QR code/variable data, labour

charges, and cost of all consumables including cost of print heads.

12. The bidder on request should present trial run in Barcoding unit Model

KodakVIS1200(K600i) with compatible/suitable consumables and spares which do not

cause any damage to barcoding machine.

13. If any damage occurred to the barcoding machine, during/due to the trial run, it will be

the sole responsibility of the bidder to repair the bar coding machine.

14. The party should maintain the optimum temperature and humidity required for the proper

functioning of the barcoding system/associated equipments, chemicals used by them and

will be responsible for troubleshooting, up keeping of the required parameters for

efficient functioning of the bar coding system/associated equipments.

15. The successful party/contractor should arrange their own space/office to store all

consumables required for click operation and KBPS will not be responsible for any

loss/missing of such consumables.

16. The successful party/contractor should arrange the food and accommodation related to

the employees engaged by them.

17. The successful party/contractor will be liable for penalization in view of any

defects/irregularities/bar-coding challenges in barcode/QR code/other variable data

printing, additional wastage (excess wastage consumed) of paper incurred to the Society

for click operation (2% wastage is allowed), any breach/ failure in security aspects, delay

occurred in barcode/QR code /variable data printing.

18. The successful party/contractor will be liable for the revenue loss incurred on the part of

KBPS due to the poor quality of ink/consumables used for barcode/QR code /variable data

printing.

19. The successful party/contractor should be responsible for the proper checking of the

numbered labels and in case of any mistake they shall be responsible for the loss and

damages and further consequences their upon.The successful party/contractor shall

indemnify and keep indemnified KBPS all such loss or damages caused to it due to any

act, omission, negligence, lapses on the part of the successful party/contractor.

20. Payment will be made only after the execution of work in definite intervals on

presentation of certified bill.

KERALA GAZETTE

Part IV

____________________________________________________________________________________________________________________________

This is a digitally signed Gazette.

Authenticity may be verified through https://compose.kerala.gov.in/

Page 3 of 5

21. The successful party/contractor will be liable for all statutory payments including

ESI,PFetc of permanent or non-permanent staff engaged by them and the details should

be produced if required. .

22. As the machine at KBPS is running in 3 shifts, the successful party/contractor should post

trained/skilled personals in all the 3 shifts for operating barcode/QR code/variable data

system and for printing corrections and the service of one technically skilled supervisor

should be available daily at KBPS.

23. Parties/contractors who have defaulted in executing any purchase order/contract with

KBPS or whose purchase order/contract were terminated by KBPS are not eligible to

participate in this tender.

24. The near relatives of employees of KBPS are not eligible to participate in the tender. The

relationship for the purpose of rule will be as specified in Stores Purchase Manual of

Kerala (extract given as Annexure A). The scanned copy of the declaration (annexure B)

in this regard, duly filled and signed should be submitted online.

25. The scanned copy of agreement in Rs. 200/- Kerala stamp paper duly filled and signed

shall be submitted online. The offer without agreement in ` 200/- Kerala stamp paper will

be rejected outright.

26. The successful bidder should furnish a performance security equivalent to 5% (five

percent) of the contract price for the due performance of the contract and to execute an

agreement in Rs. 200/- stamp paper, which is valid for 14 months as per the specimen

agreement incorporating the terms and conditions applicable for the work, within 10 days

from the date of the Work Order.

27. The indenting tenderers, if required, can visit the system during working hours on or

beforedue date of this e-tender.

28. Bidders are requested to quote rates in the price schedule (BOQ) only. The basic rate

(including all costs as stated above), GST should be quoted separately in the respective

columns of BOQ. Please do not quote/mention rates anywhere else in the tender other

than BOQ.

29. The rate for printing variable data /barcode with QR code per ticket shall be applicable

for a period of 1 year (One year). The price shall be firm and shall not be liable to

change, under any circumstances.

30. The successful party/contractor will not underlet or sublet the execution of the click

operation.

31. The variable data of each ticket provided by KBPS should be kept in safe custody of

successful party/contractor until the work is completed and should be returned to KBPS

after the execution of the click operation forthwith. The variable data and the softwares

used for the processing of variable data provided by KBPS shall not be shared with any

outside parties or firms. Any failure in security aspects from the part of successful

party/contractor will be viewed seriously and suitable penalty will be imposed.

32. The successful party/contractor should print the bar code/QR code and variable data only

in the required number of tickets for each of the lotteries as per the order placed by KBPS

from time to time and that no tickets should be bar coded/ QR coded in excess of the

numbers specified in the work order from KBPS.

33. The successful party/contractor should deliver the bar coded, QR coded and variable data

printed tickets before 20 days of the date of draw/ at least 7 days before the date of release

of tickets whichever is earlier or at a reasonable earlier date specified by KBPS.

08th September 2026

KERALA GAZETTE

____________________________________________________________________________________________________________________________

This is a digitally signed Gazette.

Authenticity may be verified through https://compose.kerala.gov.in/

Page 4 of 5

34. The successful party/contractor shall carry out the click operation of each ticket in

accordance with the time schedule prescribed by KBPS without any failure. Any delay

occurred in the supply of bar coded/ QR coded tickets will be viewed seriously and

penalized accordingly.

35. The successful party/contractor shall ensure that workmanship will be the best. The

successful party/contractor shall also agree that any failure in this regard, KBPS shall have

the right to terminate the work, at any stage, without notice. The whole work shall be

carried out inside the premises using the manpower of the successful party/contractor.

There is no employer employee relationship exists between KBPS and the successful

party/contractor and its employees.

36. The successful party/contractor shall be responsible for maintaining proper records and

registers as required under various statutes and shall pay required contributions in

respect of its employees, such as ESI, EPF etc.,

37. KBPS shall not be responsible for making any payment to anybody or authority with

respect to the employees engaged bythe successful party/contractor for carrying out the

subject work. In case, if KBPS is made liable to make any payment, to anybody or

authority, the successful party/contractor shall indemnify KBPS, to the full extent of such

expenses, loss or damages caused to KBPS in this regard.

38. The workers engaged by the successful party/contractorshall strictly follow the Security

rules of KBPS inside the premises.

39. If workers are engaged on holidays, the successful party/contractor shall obtain prior

permission from the concerned officials of KBPS.

40. Details regarding the name of the workers engaged by the successful party/contractor

shall be entered in the register maintained in the Time Office of KBPS.

41. It

the

responsibility

ofthe

successful

party/contractorto

provide

working

equipments/tools for the works.

42. The successful party/contractor is exclusively responsible for the safety of the workers

engaged by them. The successful party/contractor shall take proper insurance to cover all

probable risk, including but not limited to Employees Compensation. Any loss/damage

caused to the machinery shall be the sole responsibility of the successful party/contractor.

43. The successful party/contractor shall take care to see that no damage is caused to any

materials/assets inside the premises of KBPS. In case of damage to any materials, it shall

be the sole responsibility of the successful party/contractor to repair or replace it at their

cost. In case of any failure on the part of the successful party/contractor in this regard,

KBPS shall repair or replace the same and recover the expenses from the successful

party/contractor or any amount due to them.

44. The KBPS management reserves the right to cancel/terminate the contract/order without

assigning any reason whatsoever and recover the damages/penalty from the successful

party/contractor and to assign whole or part of the contract/order to any other party.

45. Smoking, usage of intoxicants or any other kind of indisciplinary activities are strictly

prohibited inside the premises of KBPS. Violation of the same by The successful

party/contractor or its employees, KBPS shall have the right to terminate the work

forthwith and recover the loss or damages caused to it in this regard. KBPS shall have the

right to amend the terms and conditions of this work order after intimating it to the

successful party/contractor.

KERALA GAZETTE

Part IV

____________________________________________________________________________________________________________________________

This is a digitally signed Gazette.

Authenticity may be verified through https://compose.kerala.gov.in/

Page 5 of 5

46. Any dispute or differences, in respect of this work order shall be referred to a sole

arbitrator to be appointed by KBPS and the venue of arbitration shall be at Ernakulam.

The provisions of Arbitration and Conciliation Act, 1996 as amended by amendment act

2015 will govern such proceedings.

47. All the rights to accept or reject whole or part of the tender without assigning any reason

thereof is reserved by KBPS. The decision of KBPS will be final and binding on the

tenderer.

48. All the rules and regulations of the Tender/bid shall be in accordance with the Stores

Purchase Manual of the Government of Kerala.

Sd/-

MANAGING DIRECTOR

08th September 2026

KERALA GAZETTE

____________________________________________________________________________________________________________________________

This is a digitally signed Gazette.

Authenticity may be verified through https://compose.kerala.gov.in/

In the Court of The Additional Sub Judge, Kottayam

Present : SMT. SONY, A. S., Additional Sub Judge (In-Charge)

Monday the 6th day of April, 2026/16th day of Chaitra, 1948.

I.A. 05/2026 in OP (Insolvency) 04/2018

Petitioner :-

ADV. P. K. VINODKUMAR,

Special Receiver.

Counter Petitioners :-

1. K.V. Viswanathan (Died), aged 68 years, S/o. Vasudeva Panikkar, residing at

Kunnathukalathil Jino Bhavan, Thekkumgopuram, Thirunakkara Kara, Kottayam P.O.,

Kottayam Village, Kottayam Taluk, Kottayam District-686 001.

2. Ramani Viswanathan, aged 74 years, W/o. K.V. Viswanathan, residing at

Kunnathukalathil Jino Bhavan, Thekkumgopuram, Thirunakkara Kara, Kottayam P.O.,

Kottayam Village, Kottayam Taluk, Kottayam District-686 001.

CP 1 Died

CP 2 By Adv. K. C. Eldho, Adv. Jijo Thomas, Adv. Mallenathan M., Adv. Anitha V. R. &

Adv. Aneesh James.

This petition coming up for consideration on 6-4-2026 and court on the same day passed the

following.

ORDER

Petition allowed. Produce Gazette notification and paper publication published in the leading

newspaper 19-5-2026.

Pronounced in open court on this the 6th day of April, 2026.

SONY, A. S.,

Additional Sub Judge

(In-charge).

APPENDIX:- Nil

(Id.)

Additional Sub Judge.

(Sd.)

AMRITHA, T.,

Additional Sub Judge.

For SONY, A. S.,

Additional Sub Judge

(In-charge).

KERALA GAZETTE

Part IV

____________________________________________________________________________________________________________________________

This is a digitally signed Gazette.

Authenticity may be verified through https://compose.kerala.gov.in/

IN THE COURT OF THE HONOURABLE ADDITIONAL SUB COURT, KOTTAYAM

Insolvency Petition No. 4 of 2018

Petitioners/Debtors

Respondents

1. K.V. Viswanathan

NJT Finance Pvt. Limited & others

Kunnathukalathil

2. Ramani Viswanathan

do.

NOTICE (FORM NO.12)

Issued under section 31 & Rule XXI of the Kerala Insolvency Act 1955.

The petitioners herein submitted the above numbered Insolvency Petition for adjudging them as

Insolvents before this court on 19-6-2018. In the above case the petitioners were adjudged as Insolvents

on 12-3-2026. By the order the Insolvents are directed to apply for discharge within 6 months.

The creditors are directed to submit the claim petitions in Form No. 5 of the Kerala Insolvency Rules with

the supporting documents in original.

(Sd.)

Sub Judge

Kottayam,

Addl. Sub Court (Insolvency Court),

4-4-2026.

Kottayam.

08th September 2026

KERALA GAZETTE

____________________________________________________________________________________________________________________________

This is a digitally signed Gazette.

Authenticity may be verified through https://compose.kerala.gov.in/

____________________________________________________________________________________________________________________________

PUBLISHED BY THE SUPERINTENDENT OF GOVERNMENT PRESSES

AT THE GOVERNMENT CENTRAL PRESS, THIRUVANANTHAPURAM, 2026