THE
JHARKHAND GAZETTE
EXTRAORDINARY
PUBLISHED BY AUTHORITY
4 BHADRA, 1944 (S)
No. 422
RANCHI, FRIDAY 26TH AUGUST, 2022
COMMERCIAL TAXES DEPARTMENT
--------
NOTIFICATION
26th August, 2022
Sub: Standard Operating Procedure (SOP)/Directive for post-GST payments of pending
bills related to work orders issued during pre-GST period.
S.O. No. 33 Dated 26 August, 2022--The matter relates to the Works Contract awarded by the State Government departments/ local authorities in the pre GST period and payments and execution of those Works Contract Services (partly or wholly) is to be made in the post GST period i.e. from 1.07.2017.
The Goods and Services Tax (GST) has come into force w.e.f 1st July 2017 by subsuming various indirect taxes such as Central excise duty, Service tax VAT, CST, Entry tax, etc. Subsequent to the enactment of GST Act w.e.f. 01.07.2017, different work departments of State Government have sought clarifications on modalities of treatment of pending bills of different contractors where in the contract was awarded in pre-GST regime, i.e., VAT regime and the works has completed partly/wholly after the implementation of GST. Hon'ble Jharkhand High Court has directed the Government of Jharkhand to issue guidelines on this matter in its order dated 16-03-2021 in WP (T)- 2108/2019.
2 Jharkhand Gazette (Extraordinary), Friday, 26th August, 2022The main issue under consideration is for the payment of pending bills related to work order issued during pre GST period and supply of Works Contract services is executed under GST regime which is discussed as below;-
1. The term "Works Contract" is defined under sec 2(lxiii) of JVAT Act, 2005 as follows- " Works Contract" means and includes any agreement for carrying out for cash or deferred payment or other valuable consideration, for assembling, construction, fabrication, erection, installation, modification, fitting out, improvement or repair of any building, road, bridge or commissioning of any other immovable or movable property.
2. The term "Works Contract" is defined under sec 2(119) of JGST Act, 2017 as follows- " A contract for building, construction, fabrication, completion, erection, installation, fitting out, improvement, modification, repair, maintenance, renovation, alteration or commissioning of any immovable property wherein transfer of property in goods (whether as goods or in some other form) is involved in the execution of such contract".
As per Para 6(a) of schedule II of JGST Act, 2017, Works Contract as defined in Sec 2(119) shall be treated as supply of Services.
3. Under JVAT Act 2005, works contracts covered both movable and immovable property whereas "Works Contract" under GST is restricted only to immovable property. In this context, under GST, construction, building, erection, installation services etc. involving supply of both taxable goods along with labour and other services may be construed as composite supply*.
4. The term composite supply is defined under Sec 2(30) of the GST Act as follows:-
*Composite supply means a supply made by a taxable person to a recipient consisting of two or more taxable supplies of goods or services or both or any combination thereof, which are naturally bundled and supplied in conjunction with each other in the ordinary course of business, one of which is a principal supply.
Illustration: Where goods are packed and transported with insurance, the supply of goods, packing materials, transport and insurance is a composite supply and supply of goods is a principal supply.
In such cases the rate of tax shall be determined by applicable rate on principal supply.
5. Before introduction of the GST, the tax was levied separately on services as service tax by the central government and on goods used in the works contract attracted central excise duty of centre and vat of state government. For any Works contract, the goods attracted central excise duty and VAT and Services attracted service tax.
3 Jharkhand Gazette (Extraordinary), Friday, 26th August, 2022| Works Contract tasks | Tax type |
| Supply of Goods | VAT |
| Supply of Services | Services Tax |
| If a new product emerges while a Work Contract is being completed | Central Excise Duty |
6. During VAT regime materials used in works contract or the goods as it may be called, were taxable @5%, 5.5% or 14.5% or 14% and labour charges were n o t ta x ab le . Also, the rate of Tax Deduction under JVAT Act was at Source (TDS) @ 4%. Whereas the Central taxes were levied as service tax on services given by way of labour, design, architect etc. and central excise duty on such goods manufactured.
7. Keeping in view the difficulties faced and feedback received so far and in compliance to the direction given by the Hon'ble High Court of Jharkhand an SOP is being issued in consultation with the departments concerned and after the approval of the Competent Authority.
8. Under the GST tax regime, the rate of GST on Works Contracts for Government work was notified at 18% vide notification no-11/2017,CT(R) dated 28.06.2017. However, the rate of GST on Works Contracts for Government work was reduced to 12% [Notification no. 20/2017- CT (Rate) dated 22.08.2017].
However, vide Notification No. 22/2021,CT (Rate) Dated – 31/12/2021, rate has
been changed to –
| Services | Rate of Tax | w.e.f |
| Work contract services provided to Government authorities and Government entity. | 18% | 01-01-2022 |
Vide Notification No. 03/2022, Dated – 13/07/2022
| Services | Rate of Tax | W.e.f |
| Work contract services provided to central Government, state Government and local authorities. | 18% | 18-07-2022 |
| Composite supply of works contract involving predominantly earth work (that is constituting more than 75 % of the value of the work contract) provided to the central Government, state Government, local authorities. | 12% | 18-07-2022 |
So in the period between 22.08.2017 till 17.07.2022 the rate of GST on Works contract has been @ 12% for the service supplied to central government state government and local authority.
9. Incidence of applicable taxes of Service Tax/VAT/ GST
Incidence of the applicable taxes shall be as follows:-
| Sr. No. | Completion of works contract | Invoice Date | Payment Date | Applicability of Taxes | Applicable TDS | ||
| Service Tax | VAT on Material used | GST | |||||
| 1 Up to 30.06.2017 | Up to 30.06.2017 Up to 30.06.2017 | Yes | Yes | No | VAT TDS | ||
| 2 Up to 30.06.2017 | Up to 30.06.2017 After 30.06.2017 | Yes | Yes | No | VAT TDS | ||
| 3 Up to 30.06.2017 | After 30.06.2017 | After 30.06.2017 | No | No | Yes | GST TDS * | |
| 4 | From 01.07.2017 | From 01.07.2017 | From 01.07.2017 | No | No | Yes | GST TDS * |
| * TDS under GST is made applicable w.e.f. 01.10.2018. Provision of TDS was not applicable between 01.07.2017 to 30.09.2018 |
10. Availability of Input Tax Credit (ITC) under GST
i. Unlike the VAT regime, where ITC of central taxes (Service tax and central excise duty) were not available for discharging state tax liability, and the credit of CST was also not available, under GST all this taxes whether levied under SGST, CGST and IGST is available for ITC credit (Except for credit of SGST/CGST only restricted to SGST/CGST liability respectively). Further the ITC of both goods and services are now available.
Thus it removes the cascading effect of tax by facilitating seamless flow of credit. The aim of GST is to remove the restrictions of ITC credit in the supply chain.
In the GST regime, the input tax credit of IGST, CGST and SGST charged on any supply of goods and/or services used or intended to be used inthe course of furtherance of business is permissible. Works Contractor is eligible to avail ITC credited to his electronic credit ledger on GST portalsubject to conditions prescribed therein.
It is also pertinent to mention that under GST regime cross utilization of credit of Goods and Services are available to offset ones liability which was not available during the pre GST regime.
ii. It is also important to mention that under GST works contractors are eligible for availing transitional ITC on stock of Goods purchased from 01.07.2016 onwards and declared in the returns filed, by way of filing TRAN-1 and TRAN-2.
5 Jharkhand Gazette (Extraordinary), Friday, 26th August, 2022
11. Payments for Work Contracts
The contract price is generally inclusive of all taxes in most of the contracts; these taxes have now been subsumed under GST. In order to arrive at the incidence of applicable VAT/ Service Tax/ GST as mentioned at Para 9 above, the total work shall becategorized as follows:
(i) Works completed up to 30.06.2017 and Billing completed by 30.06.2017.
(ii) Works completed up to 30.06.2017 and Billing not completed by30.06.2017.
(iii) Works yet to be completed as on 01.07.2017.
JGST Act, 2017 shall be applicable for all the works mentioned above at (ii) & (iii).
12. Following procedure may be adopted by various Executing Agencies/Authorities for
calculating the incidence of tax while making payments as per the provisions in the contracts:-
i. The Goods and Services in the various project under different major heads (like Earth, Sand, Steel, Cement, Bitumen etc.) and for services (design, consultancy, security, architect etc.) are to be intimated by the contractor and checked/ confirmed by the respective executing agencies/authorities in consultation with the concerned higher authority/technical wing for each of theProject.
ii. In order to compile the above information, an indicative Excel format is suggested for guidance and attached as (Annexure-1). It indicates various Goods and Services in the various project which attract various rates of taxes including Central Excise Duty, CST, VAT and other taxes, which were already included in the contract price as per the original contract.
iii. Under VAT regime, Rate of tax on major commodities used in Works contract
| Commodities | VAT(Rate of Tax) | Central Excise Duty (Rat e of Tax) |
| Steel | 5 % | 12.36 % |
| Cement | 14.5 % | 12.36 % |
| Bitumen | 5.5 % | 12.36 % |
For rate of Tax on other commodities Part B of schedule II of JVAT 2005 and First Schedule and the Second Schedule to the Central Excise Tariff Act,1985 may be referred to.
6 Jharkhand Gazette (Extraordinary), Friday, 26th August, 2022Similarly under GST, Rate of Tax on Goods and Services were:-
| Commodities | GST(Rate of Tax) |
| Steel | 18 % |
| Cement | 28 % |
| Bitumen | 18 % |
For detailed rates of tax on other Goods and Services involved in execution of work contracts, schedule I, II, III and IV to JGST 2017 may be referred to.
iv. The same format can be used to compile the information for each ongoing project. The Goods and Services in the various project should be checked and verified by the concerned works department on the basis of bill of quantity, estimate, schedule of rate and other technical specifications. The Pre-GST rate of tax such as Central excise duty/ VAT on materials and service tax on services and post-GST rates (of SGST, IGST, CGST) on supply of works contract should be checked and verified.
v. After completion of the said exercise, the costs on account of the subsumed taxes under pre GST and post GST in the particular contract are to be finalized and agreed by concerned state department and Contractor. That is to say the incidence of tax in pre GST and post GST should be calculated that has been factored in the cost of project. The cost so arrived at be compared from the original contract price to arrive at the actual balance of cost of the project i.e. whether there is an increase or decrease in cost of the project.
vi. The state work department may receive certification from any accredited agencies/charted accountant as deemed fit and accordingly the concerned state department shall assess the incidence of total tax (inclusive of central and state taxes) applicable in the pre GST regime and compare it with the total incidence of tax as applicable on such goods and services under the GST regime.
vii. While calculating the positive or negative impact of GST, the state department must keep in mind the availability of ITC of goods and services both in case of GST unlike in the VAT regime where ITC of services were not available.
13. After comparing the net increase/decrease in tax liability to the total tax levied under VAT regime and GST regime and also accounting the ITC availability, any conclusion regarding negative or positive impact on cost may be arrived at.
14. It may be clarified that under no circumstances there will be a revision of any contractual values in the contract, in cases where the work has to be completed before 30.06.2017 as per the contract, but the execution got delayed as a result of delay on part of the contractor.
7 Jharkhand Gazette (Extraordinary), Friday, 26th August, 202215. No revision of contractual value should be considered if there is no clause for ange in the rate of tax is mentioned in the contract.
16. As per section 51 of the Jharkhand GST Act, 2017 / the Central GST Act, 2017, GST– TDS @ 2 % (1% CGST + 1 % SGST) must be deducted after 01.10.2018 from payments to contractors / suppliers.
17. The Administrative Departments should issue suitable instructions to the competent agency/authority responsible for making payments to the works contractors to implement this directive/SOP.
18. For the sake of convenience and to explicitly explain the procedure for calculation of incidence of tax in Pre and Post GST regime is being explained with an example in Annexure I.
(File No. Va.Kar/Vividh/20/2020) By the order of the Governor of Jharkhand,
Aradhana Patnaik, Secretary, Commercial Taxes Department, Jharkhand, Ranchi.
Project/ Contract details
Table- I
| Gross Original Value of the Works Contract given prior to GST implementation | Value of of the Works Contract rendered upto 30.6.2017 as per original contract | Balance value of the Works Contract to be rendered after 01.07.2017 | Remarks |
| Rs. 200000 | Rs. 100000 | Rs. 100000 | Half value of the work completed before GST and rest after GST |
Considering half the value of work i.e. of Rs. 1,00,000 is done in the
post GST period i.e. after 01.07.2017, the breakup of the
*
material/service cost is as under-
Table- II
| Project Contituents | Percentage of Contituents | Gross Original Value of the Contract Total | Pre GST | Post GST | |
| (a) Gross Value of Contract | 200,000 | 100,000 | 100,000 | ||
| (b) Less: Margin | 20,000 | 10,000 | 10,000 | ||
| (c) Cost of the Project (a-b) | - | 180,000 | 90,000 | 90,000 | |
| (d) Bitumen | 17% | 30,600 | 15,300 | 15,300 | |
| (e) Steel | 8% | 14,400 | 7,200 | 7,200 | |
| (f) Cement | 12% | 21,600 | 10,800 | 10,800 | |
| (g) Aggregates, Sand etc | 16% | 28,800 | 14,400 | 14,400 | |
| (h) Pipes | 1% | 1,800 | 900 | 900 | |
| (i) Oth. Materials | 1% | 1,800 | 900 | 900 | |
| Electrical item | 15% | 27,000 | 13,500 | 13,500 | |
| Labour | 30% | 54,000 | 27,000 | 27,000 | |
| 100% | 180,000 | 90,000 | 90,000 | ||
| Project/ Contract details |
account of increase in incidence of tax due to implementation of GST. A comparision has been made on that half
value of the left work i.e. Rs. 1,00,000 with incidence of tax in pre and post GST and their effective cost on the
project on account of these taxes thereof.
Table- III
| GST Implica tions (For balanc e work) | Pre GST | GST | ||||||||
| Basic price (Cost excluding Output VAT, Input VAT & Excise/ Service Tax) | Excise duty/ service tax rate and its amount of Excise duty/Ser vice tax | Input VAT rate and amoun t of input VAT | Output VAT rate and output VAT consideri ng VAT Input | Cost Incl. all taxes & duties | GST rate | GST Amou nt | GST 12% work contrac t | Total cost under GST consider ing GST Input | Excess cost due to GST | |
| 1 | 2 | 3 | 4 | 5 | 6 | 7 | 8 | 9=(2+8) @ 12% | 10=(2+8 ) | 11 |
| Cost of the p rojec t (a-b) | 90,00 0 | 12% | ||||||||
| Bitum en | 12,912 | 12% (1549) | 5.5% (795) | 5.5% (44) | 15,30 0 | 18% | 2,324 | 1,828 | 14,740 | |
| Steel | 6,108 | 12% (733) | 5% (342) | 5% (17) | 7,200 | 18% | 1,099 | 865 | 6,973 | |
| Ceme nt | 8,270 | 12% (992) | 14.5% (1343) | 14.5% (195) | 10,80 0 | 28% | 2,316 | 1,270 | 9,540 | |
| Aggre gates, Sand etc | 13,612 | 0% (0) | 5.5% (747) | 5.5% (41) | 14,40 0 | 5% | 681 | 1,715 | 15,327 | |
| Pipes | 763 | 12% | 5% | 5% | 900 | 18% | 137 | 108 | 871 | |
| (92) | (43) | (2) | ||||||||
| Oth. Materi als | 693 | 12% (83) | 14% (109) | 14% (15) | 900 | 18% | 125 | 98 | 791 | |
| Electri cal items | 10,337 | 12% (1240) | 14.5% (1679) | 14.5% (244) | 13,50 0 | 0% | 0 | 1,240 | 11,577 | |
| Labou r | 23,478 | 15% (3522) | 0% (0) | 0% (0) | 27,00 0 | 0% | 0 | 2,817 | 26,295 | |
| Cost of the p rojec t | 76,173 | 8211 | 5058 | 558 | 90,00 0 | 6,682 | 9,943 | 86,115 | -3,885 | |
In above example it is assumed that cost of project inclusive of all taxes and duties excluding
* profit margin is Rs. 90,000 as shown in column '6'.
The base price in column 2 has been arrived by back calculation from column 6 after deducting VAT
output considering VAT input, VAT input and Excise duty/service tax as mentioned in column 5,4,3
*
respectively .
So the aggregate cost arrived at in pre GST is Rs. 76173 + Rs. 8211(on account of central excise duty/
service tax) + Rs. 5058 (VAT on the raw material) + Rs. 558 (VAT on final works contract adjusting ITC)
*
totaling to Rs. 90,000.00.
For sake of convenience, the education cess and secondary & heigher education cess has not been
*
considered for calculation of central taxes in above example.
GST
Considering the base price of goods and services as specified in column 2, and applying the applicable
* GST rate on such material/ services, the GST amount of RS. 6,682 has been calculated in column 8.
* During the period of 22.08.2017 to 17.07.2022 the GST rate on works contract has been 12%.
The GST rate of 12% on supply of works contract services would be applicable on the sum of basic price
*
of Rs. 76,173 specified in column 2 and GST amount as specified in column 8.
So the aggregate cost arrived in GST period is Rs. 76,173 + Rs. 9,943 adjusting the ITC, totaling amount
* Rs. 86,115 which is Rs. 3,885 less than pre GST period.
--------
झारख(cid:214)ड राजक(cid:551)य मु(cid:289)णालयझारख(cid:214)ड राजक(cid:551)य मु(cid:289)णालय,, राँची (cid:622)वारा (cid:292)का(cid:871)शत एवं मु(cid:465)(cid:289)तराँची (cid:622)वारा (cid:292)का(cid:871)शत एवं मु(cid:465)(cid:289)त,,
झारख(cid:214)ड गजट झारख(cid:214)ड गजट ((असाधारणअसाधारण) ) 442222 ---- 5500