Kerala Gazette, No. 36, Part Part IV, 08 September 2026

click here for IIIF manifest

Regn.No. KERBIL/2012/45073

dated 2012-09-05 with RNI compose.kerala.gov.in egazette.kerala.gov.in

Reg No.KL/TV(N)/634/2021-2023 printing.kerala.gov.in

മകരള സരകാര

GOVERNMENT OF KERALA

മകരള ഗസറ് KERALA GAZETTE

ആധികാരികാേയി ്പസിദറ്റപടുതുനത

PUBLISHED BY AUTHORITY

ചചാവ, 2026 ചസപറംബര 08

Tuesday, 08th September 2026

1202 ചിങം 23

1948 ഭാ്ദം 17

23rd Chingam 1202

17th Bhadra 1948

വാലം 15

നരേ 36

No.

Vol. XV

Part IV

Miscellaneous Notifications

©

മകരള സരകാര

GOVERNMENT OF KERALA

2026This is a digitally signed Gazette. Authenticity may be verified through https://compose.kerala.gov.in/

കേരള കേറ്റ് ഇലക്ട്രിസിറ്റി ക ോര്‍ഡ് ലിറിറ്റഡ്

അറിയിപ്പ്

നമ്പര്‍. ഡി. ി-ഗസറ്റ്/2026-27/280 തീയതി : 18.08.2026 (ഇന്ത്യന് ഇലക്ട്രിസിറ്റി ആക്ട് 2003 ലല 164 ലസക്ഷന് 185(2) (a)(b) വകുപ്പ് പ്രേോരം ല ോതുജനങ്ങളുലെ അറിവികലക്കോയി രസയലപ്പടുത്തുന്നത് )

കേരള സംസ്ഥോനത്തിലല വര്‍ധിച്ചു വരു വന ന്ന യവതി ഉതി ഗ കയോഗത്തിന് രിഹോരറോയി, ആലപ്പുഴ ജില്ലയിലല നിലവിലുള്ള 66 ലേ വി യലന് പുനന ധോരണ പ്രവര്‍ത്തനങ്ങക്ക്കോയി ലേ.ഇസ്.ഇ. ി. ലിറിറ്റഡിലല ഗകതി യോഗസ്ഥകരോ അവര്‍ ചുറതലലപ്പടുത്തുന്ന ററ്റു വയക്തിേകളോ ജില്ലയിലല തോലഴ ലേോടുത്തിരിക്കുന്ന സ്ഥലങ്ങളില് 110 ലേ.വി ഡ ിക് സര്‍േൂട്ട് ് യലന് േെന്നുക ോേോന് ഗകേശിക്കുന്ന സവേോരയ ഭൂറിേക് ഗക്ലപ്പലെയുള്ള നിലവിലല 66 ലേ വി േെന്നുക ോകുന്ന വസ്തുക്കളില് കൂെി അവന ലെ നിയറോനുസൃതറോയ കൃതയനിര്‍വഹണത്തിലെ ഭോഗറോയി നിശ്ചിത സറയങ്ങളില് പ്രകവശിക്കുന്നതോലണന്നുള്ള വിവരം ന്ധലപ്പട്ട് ഇല്ലോവലരയും ഇതിനോല് അറിയിച്ചു വരു ലേോള്ളുന്നു. പ്രസ്തുത കജോലിേക് ലെയ്യുന്നതില് നിന്നും അവലര തെസ്സലപ്പടുത്തുന്നത് നിയറ വിന ധറോലണന്നും അറിയിക്കുന്നു.

ഒപ്പ് /- ലഡ ൂട്ട് ി െീഫ് ഇന്ജിനീയര്‍ ട്രോന്സ്മിഷന് സര്‍ക്കിക് , ആലപ്പുഴThis is a digitally signed Gazette. Authenticity may be verified through https://compose.kerala.gov.in/

In the Court of The Additional Sub Judge, Kottayam Present : SMT. SONY, A. S., Additional Sub Judge (In-Charge)

Monday the 6th day of April, 2026/16th day of Chaitra, 1948.

I.A. 05/2026 in OP (Insolvency) 04/2018

Petitioner :- ADV. P. K. VINODKUMAR, Special Receiver.

Counter Petitioners :-

1. K.V. Viswanathan (Died), aged 68 years, S/o. Vasudeva Panikkar, residing at Kunnathukalathil Jino Bhavan, Thekkumgopuram, Thirunakkara Kara, Kottayam P.O., Kottayam Village, Kottayam Taluk, Kottayam District-686 001.

2. Ramani Viswanathan, aged 74 years, W/o. K.V. Viswanathan, residing at Kunnathukalathil Jino Bhavan, Thekkumgopuram, Thirunakkara Kara, Kottayam P.O., Kottayam Village, Kottayam Taluk, Kottayam District-686 001.

CP 1 Died

CP 2 By Adv. K. C. Eldho, Adv. Jijo Thomas, Adv. Mallenathan M., Adv. Anitha V. R. & Adv. Aneesh James.

This petition coming up for consideration on 6-4-2026 and court on the same day passed the following.

ORDER

Petition allowed. Produce Gazette notification and paper publication published in the leading newspaper 19-5-2026.

Pronounced in open court on this the 6th day of April, 2026.

SONY, A. S., Additional Sub Judge (In-charge).

APPENDIX:- Nil

(Id.) Additional Sub Judge.

(Sd.)

AMRITHA, T., Additional Sub Judge. For SONY, A. S., Additional Sub Judge (In-charge).

IN THE COURT OF THE HONOURABLE ADDITIONAL SUB COURT, KOTTAYAM

Insolvency Petition No. 4 of 2018

Petitioners/Debtors Respondents

1. K.V. Viswanathan NJT Finance Pvt. Limited & others Kunnathukalathil

2. Ramani Viswanathan

do.

NOTICE (FORM NO.12)

Issued under section 31 & Rule XXI of the Kerala Insolvency Act 1955.

The petitioners herein submitted the above numbered Insolvency Petition for adjudging them as Insolvents before this court on 19-6-2018. In the above case the petitioners were adjudged as Insolvents on 12-3-2026. By the order the Insolvents are directed to apply for discharge within 6 months.

The creditors are directed to submit the claim petitions in Form No. 5 of the Kerala Insolvency Rules with the supporting documents in original.

(Sd.)

Sub Judge

Kottayam, Addl. Sub Court (Insolvency Court), 4-4-2026. Kottayam.

(cid:2)(cid:3)(cid:4)(cid:5)(cid:6)(cid:7)(cid:8)(cid:9)(cid:10) (cid:11)(cid:12)(cid:4)(cid:13)(cid:14)(cid:4)(cid:15)(cid:16) (cid:14)(cid:17)(cid:18) (cid:19)(cid:20)(cid:6)(cid:10)(cid:21)(cid:4) (cid:22)(cid:9)(cid:23)(cid:6)(cid:24)(cid:20)

(cid:2)(cid:3)(cid:4) IP 5/2024.

(cid:5)(cid:4)(cid:6)(cid:7)(cid:8)(cid:9)(cid:10)(cid:11):— (cid:13)(cid:14)(cid:9)(cid:15)(cid:16)(cid:17)(cid:18)(cid:19)(cid:4) (cid:20)(cid:9)(cid:21)(cid:19)(cid:8)(cid:22), (cid:24)(cid:14)(cid:25)(cid:26)(cid:27)(cid:28)(cid:21)(cid:27) (cid:29)(cid:7)(cid:30)(cid:18)(cid:6)(cid:22), (cid:29)(cid:31)(cid:7) (cid:3)(cid:21)(cid:27) (cid:30)!"#(cid:22) (cid:14)$(cid:8)(cid:27) (cid:29)%&(cid:7)' (cid:30)(cid:29)(cid:21)(cid:9) (cid:16)((cid:11) (cid:26)(cid:14)(cid:11) ")(cid:9)(cid:27)*+(cid:14)(cid:9)"(cid:22)

,-(cid:9)(cid:27) .(cid:20)/(cid:14)0(cid:7):— 1234(cid:11)5(cid:22) (cid:14)(cid:16)4%5(cid:22) (cid:24)*+(cid:29)6(cid:22) (cid:21)(cid:7)(cid:26)(cid:7)67(cid:22), 8(cid:10)(cid:7)(cid:17)(cid:9)(cid:21)(cid:8)(cid:16)(cid:15) .- 9(cid:9)+(cid:2)#(cid:7)(cid:2)(cid:16)(cid:30)(cid:29):(cid:7) 8(cid:30)(cid:25)(cid:9)(cid:31)(cid:13)# (cid:26)(cid:9)(cid:30)(cid:2)(cid:6)(cid:7)(cid:27)(cid:28)(cid:22) 7 4(cid:14)(cid:22)(cid:15)(cid:4) (cid:10):(cid:9)(cid:27) .(cid:20)/(cid:14)0(cid:7):— ,(cid:30);(cid:9)(cid:29)(cid:7) (cid:14)(cid:16)4%5(cid:22) (cid:24)*+(cid:29)6(cid:22) (cid:21)(cid:7)(cid:26)(cid:7)67(cid:22), (cid:13)+(cid:10)(cid:7)<(cid:2)(cid:27) .- 9(cid:9)+(cid:2)#(cid:7)(cid:2)(cid:16)(cid:30)(cid:29):(cid:7) 8(cid:30)(cid:25)(cid:9)(cid:31)(cid:13)# (cid:26)(cid:9)(cid:30)(cid:2)(cid:6)(cid:7)(cid:27)(cid:28)(cid:22) 7 4(cid:14)(cid:22)(cid:15)(cid:4) (cid:26)(cid:19)-(cid:9)(cid:27) .(cid:20)/(cid:14)0(cid:7):— (cid:26)(cid:9)(cid:30)(cid:2)(cid:6)(cid:4), (cid:14)(cid:2)4(cid:9) =(cid:9)>(cid:22), (cid:24)(cid:14)(cid:25)(cid:26)(cid:27)(cid:28)(cid:21)(cid:27) *=(cid:9)?(cid:22) +(cid:7).,.

(cid:24)(cid:14)(cid:25)(cid:26)(cid:27)(cid:28)(cid:21)(cid:27), (cid:13)(cid:14)(cid:9)(cid:15)(cid:16)(cid:17)(cid:18)(cid:19)(cid:4) (cid:20)(cid:9)(cid:21)(cid:19)(cid:8)(cid:22)

(cid:5)(cid:4)(cid:6)(cid:7)(cid:8)(cid:9)(cid:10)(cid:11) ,-(cid:9)(cid:27) .(cid:20)/(cid:14)0(cid:7)(cid:8)(cid:22) (cid:13)(cid:14)(cid:9)(cid:15)(cid:16)(cid:17)(cid:18)(cid:19)(cid:4) (cid:26)(cid:16)(cid:11)5(cid:7)A(cid:22) (cid:30)(cid:14)(cid:9)(cid:15)(cid:20)(cid:7) OS 990/2012-ാം (cid:2)(cid:3)(cid:4) (cid:30)(cid:14)5(cid:7)(cid:13)(cid:21) (cid:29)(cid:7)((cid:7) *+(cid:14)(cid:9)(cid:10)(cid:29)(cid:16)(cid:27), (cid:10):(cid:9)(cid:27) .(cid:20)/(cid:14)0(cid:7)(cid:8)(cid:22) (cid:15)(cid:7) (cid:26)(cid:16)(cid:11)5(cid:7)A(cid:22) (cid:30)(cid:14)(cid:9)(cid:15)(cid:20)(cid:7) OS 185/2011-ാം (cid:2)(cid:3)(cid:4) (cid:30)(cid:14)5(cid:7)(cid:13)(cid:21) (cid:29)(cid:7)((cid:7) *+(cid:14)(cid:9)(cid:10)(cid:29)(cid:16)(cid:27) (cid:26)(cid:19)-(cid:9)(cid:27) .(cid:20)/(cid:14)0(cid:7)(cid:8)(cid:22) (cid:13)(cid:14)(cid:9)(cid:15)(cid:16)(cid:17)(cid:18)(cid:19)(cid:4) (cid:21)%(cid:28)' 5(cid:4)B%5(cid:22) 1(cid:30)(cid:20)(cid:9)4(cid:7)6(cid:7) (cid:26)(cid:16)(cid:3)(cid:9)(cid:13)(cid:14) PLP 350/2016-ാം (cid:2)(cid:3)(cid:4) (cid:5)(cid:4)(cid:6)(cid:7) (cid:7)(cid:13)(cid:21) 1(cid:29)(cid:9)(cid:4)7(cid:7)(cid:13)(cid:2) (cid:20)(cid:16)(cid:15)(cid:4)-(cid:16)C 4(cid:29)(cid:2))(cid:19) 4(cid:7)(cid:8)(cid:29)4(cid:7) (cid:2)(cid:15)+(cid:15)(cid:7) *+(cid:14)(cid:9)(cid:10)(cid:29)(cid:16)(cid:27) (cid:2)'(cid:30)(cid:14):(cid:20)(cid:9) 5(cid:27)D) (cid:13)(cid:14)(cid:9)(cid:15)(cid:16)(cid:8)(cid:16)-(cid:20)(cid:7)(cid:2)(cid:16)C 5(cid:9)(cid:3)#(cid:7)(cid:14)(cid:30)"2(cid:7) (cid:5)(cid:4)(cid:6)(cid:7)(cid:8)(cid:9)(cid:10)(cid:2)(cid:7)(cid:18)(cid:9)#(cid:20)(cid:7)(cid:2)(cid:9)' (cid:5)(cid:4)(cid:6)(cid:7)(cid:8)(cid:9)(cid:10)(cid:13)(cid:2) (cid:2)(cid:7)(cid:4)E(cid:2)(cid:2)(cid:9) (cid:7) *+D)(cid:9)+(cid:7)(cid:8)$(cid:13)(cid:26)-(cid:9)(cid:29)")(cid:13)(cid:25)&(cid:22) (cid:5)(cid:4)(cid:6)(cid:7)(cid:8)(cid:9)(cid:10)(cid:11) 8(cid:11)(cid:30)5(cid:9)F(cid:13)(cid:29)(cid:11)5(cid:7) G;(cid:22) 10-ാം (cid:29)(cid:14)(cid:16)(cid:25)(cid:22) *+(cid:14)(cid:9)(cid:10)(cid:27) (cid:30)=(cid:9)((cid:7)(cid:25)(cid:7)H (cid:5)(cid:4)(cid:6)(cid:7) 15-9-2025 (cid:20)% (cid:20)(cid:7) 1(cid:2)(cid:16)(cid:29)!(cid:7)H(cid:22) (cid:5)(cid:4)(cid:6)(cid:7)(cid:8)(cid:9)(cid:10)(cid:13)(cid:2) 8(cid:11)(cid:30)5(cid:9)F(cid:13)(cid:29)I(cid:9) (cid:7) *+D)(cid:9)+(cid:7)H(cid:7)&(cid:16)C(cid:20)(cid:9)(cid:13)$- (cid:29)(cid:7)(cid:29)(cid:10)(cid:27) 8(cid:20)(cid:7)(cid:2)(cid:9)' 14(cid:7) (cid:7)(cid:8)(cid:16)-(cid:16).

J#(cid:10)(cid:29)(cid:7)(cid:11) *+(cid:14)(cid:9)(cid:10)(cid:27), (cid:29)(cid:7). (cid:6)(cid:7). 5(cid:16)K(cid:9)2(cid:22)L*M=(cid:9)=(cid:16) & G(cid:4). *+"(cid:9)N(cid:22), (cid:5)(cid:4)(cid:6)(cid:7)(cid:8)(cid:9)(cid:10)(cid:11)K(cid:9)(cid:28)(cid:27) 173(cid:30)(cid:8)6(cid:22)5(cid:22).

.

KERALA BOOKS AND PUBLICATIONS SOCIETY,

KAKKANAD, KOCHI – 682030 GST No. 32AAATK2642L1ZR e-Tender Notice for the Operating charges (click charges) for the Online bar code / QR code / variable data printing system attached with our GossWS – D 598web offset printing machine No. P1-3488/2026/3510 Date: 24.08.2026

e–Tender notice

e- tenders are invited through www.etenders.kerala.gov.infor fixing the operating charges (click charges) for printing of variable data barcoding with QR code, for the high speed online barcoding unit [Model: VIS1200 (K600i)] which is attached to the Goss WS – D 598high speed web offset printing machine with the detailed technical specificationand terms and conditions attached. Technical specification of work to be executed:

1. Print Head details : Kodak "Pros – S (10) series – Jetting module – 4.2" 2. Print width : 782mm (4.25" upto 30.8") 2. Our sheet size 600 x760 mm with 30 ups 3. One up dimension a. Small size - 193 x 70 mm b. Big size- 250 x 80 mm 4. Quantity: 180 -200crores per annum 5. Image Resolution: 600 x 600 dpi

6. Dimensions of variable data in a single label

i. 15 x 15 mm (QR code)

ii. 8 x 28 mm (Barcode)

iii. 7 x 38 mm (Alpha numeric variable data)

iv. 3 x 20 mm (Alpha numeric variable data)

v. 4 x 27 mm (Alpha numeric variable data)

vi. 3 x 40 mm (Alpha numeric variable data)

vii. 18 mm width x 3mm height (Alpha numeric variable data)

viii. 12 mm width x 2mm height (Alpha numeric variable data) - 3nos.

(The dimensions and the number of variable data may change from time to time) 7. Speed Our GossWS – D 598web offset printing machine operating speed: 25,000 - 30,000 IPH a. The variable data is to be printed on sheets of range 50-90 gsm paper b. The data printed on the tickets should be 100% dried and scratch proof. c. The barcodes and QR codes printed by the variable data printed on tickets must be 100% scannable at high speeds.

Terms and Conditions

1. All tenders/bid shall be accepted only through online mode (https:// etenders.kerala.gov.in) and no manual submission of the same shall be allowed.

2. EMD for Rs. 15,00,000/- should be remitted through online, as per the terms and conditions of the e-tender site. The benefits will be limited only to the MSMEs which are working within the state of Kerala (G.O (P) no. 10/2023/SPD dated 11.12.2023) 3. Re - submission of offer is possible, before the last date as permitted in the site. 4. Offers are acceptable only up to 11.00 am on 16.09.2026 5. Opening of bid is scheduled at 11.30 am on 17.09.2026 6. Prices should be quoted F.O.R KBPS, Kakkanad, Ernakulam, Kerala 7. The offer should be valid up to one yearfrom the date of opening of the tender. 8. The contract will be for a period of one (1) year from the date of signing, but the Management reserves the right to shorten/ extend the contract at the same rate quoted in this e- tender.

9. The successful party/contractor should provide manpower, all consumables including print heads, pigment based ink (which is tamper free and resistant to water/chemical) for running the system.

10. The successful party/contractor should provide computer, printer and manpower for carrying out the corrections in labels as per the requirement of KBPS.

11. The rate should be inclusive of printing of barcodes with QR code/variable data, labour charges, and cost of all consumables including cost of print heads.

12. The bidder on request should present trial run in Barcoding unit Model KodakVIS1200(K600i) with compatible/suitable consumables and spares which do not cause any damage to barcoding machine.

13. If any damage occurred to the barcoding machine, during/due to the trial run, it will be the sole responsibility of the bidder to repair the bar coding machine.

14. The party should maintain the optimum temperature and humidity required for the proper functioning of the barcoding system/associated equipments, chemicals used by them and will be responsible for troubleshooting, up keeping of the required parameters for efficient functioning of the bar coding system/associated equipments.

15. The successful party/contractor should arrange their own space/office to store all consumables required for click operation and KBPS will not be responsible for any loss/missing of such consumables.

16. The successful party/contractor should arrange the food and accommodation related to the employees engaged by them.

17. The successful party/contractor will be liable for penalization in view of any defects/irregularities/bar-coding challenges in barcode/QR code/other variable data printing, additional wastage (excess wastage consumed) of paper incurred to the Society for click operation (2% wastage is allowed), any breach/ failure in security aspects, delay occurred in barcode/QR code /variable data printing.

18. The successful party/contractor will be liable for the revenue loss incurred on the part of KBPS due to the poor quality of ink/consumables used for barcode/QR code /variable data printing.

19. The successful party/contractor should be responsible for the proper checking of the numbered labels and in case of any mistake they shall be responsible for the loss and damages and further consequences their upon.The successful party/contractor shall indemnify and keep indemnified KBPS all such loss or damages caused to it due to any act, omission, negligence, lapses on the part of the successful party/contractor.

20. Payment will be made only after the execution of work in definite intervals on presentation of certified bill.

21. The successful party/contractor will be liable for all statutory payments including ESI,PFetc of permanent or non-permanent staff engaged by them and the details should be produced if required. .

22. As the machine at KBPS is running in 3 shifts, the successful party/contractor should post trained/skilled personals in all the 3 shifts for operating barcode/QR code/variable data system and for printing corrections and the service of one technically skilled supervisor should be available daily at KBPS.

23. Parties/contractors who have defaulted in executing any purchase order/contract with KBPS or whose purchase order/contract were terminated by KBPS are not eligible to participate in this tender.

24. The near relatives of employees of KBPS are not eligible to participate in the tender. The relationship for the purpose of rule will be as specified in Stores Purchase Manual of Kerala (extract given as Annexure A). The scanned copy of the declaration (annexure B) in this regard, duly filled and signed should be submitted online.

25. The scanned copy of agreement in Rs. 200/- Kerala stamp paper duly filled and signed shall be submitted online. The offer without agreement in ` 200/- Kerala stamp paper will be rejected outright.

26. The successful bidder should furnish a performance security equivalent to 5% (five percent) of the contract price for the due performance of the contract and to execute an agreement in Rs. 200/- stamp paper, which is valid for 14 months as per the specimen agreement incorporating the terms and conditions applicable for the work, within 10 days from the date of the Work Order.

27. The indenting tenderers, if required, can visit the system during working hours on or beforedue date of this e-tender.

28. Bidders are requested to quote rates in the price schedule (BOQ) only. The basic rate (including all costs as stated above), GST should be quoted separately in the respective columns of BOQ. Please do not quote/mention rates anywhere else in the tender other than BOQ.

29. The rate for printing variable data /barcode with QR code per ticket shall be applicable for a period of 1 year (One year). The price shall be firm and shall not be liable to change, under any circumstances.

30. The successful party/contractor will not underlet or sublet the execution of the click operation. 31. The variable data of each ticket provided by KBPS should be kept in safe custody of successful party/contractor until the work is completed and should be returned to KBPS after the execution of the click operation forthwith. The variable data and the softwares used for the processing of variable data provided by KBPS shall not be shared with any outside parties or firms. Any failure in security aspects from the part of successful party/contractor will be viewed seriously and suitable penalty will be imposed.

32. The successful party/contractor should print the bar code/QR code and variable data only in the required number of tickets for each of the lotteries as per the order placed by KBPS from time to time and that no tickets should be bar coded/ QR coded in excess of the numbers specified in the work order from KBPS.

33. The successful party/contractor should deliver the bar coded, QR coded and variable data printed tickets before 20 days of the date of draw/ at least 7 days before the date of release of tickets whichever is earlier or at a reasonable earlier date specified by KBPS.

34. The successful party/contractor shall carry out the click operation of each ticket in accordance with the time schedule prescribed by KBPS without any failure. Any delay occurred in the supply of bar coded/ QR coded tickets will be viewed seriously and penalized accordingly.

35. The successful party/contractor shall ensure that workmanship will be the best. The successful party/contractor shall also agree that any failure in this regard, KBPS shall have the right to terminate the work, at any stage, without notice. The whole work shall be carried out inside the premises using the manpower of the successful party/contractor. There is no employer employee relationship exists between KBPS and the successful party/contractor and its employees.

36. The successful party/contractor shall be responsible for maintaining proper records and registers as required under various statutes and shall pay required contributions in respect of its employees, such as ESI, EPF etc.,

37. KBPS shall not be responsible for making any payment to anybody or authority with respect to the employees engaged bythe successful party/contractor for carrying out the subject work. In case, if KBPS is made liable to make any payment, to anybody or authority, the successful party/contractor shall indemnify KBPS, to the full extent of such expenses, loss or damages caused to KBPS in this regard.

38. The workers engaged by the successful party/contractorshall strictly follow the Security rules of KBPS inside the premises.

39. If workers are engaged on holidays, the successful party/contractor shall obtain prior permission from the concerned officials of KBPS. 40. Details regarding the name of the workers engaged by the successful party/contractor shall be entered in the register maintained in the Time Office of KBPS.

41. It is the responsibility ofthe successful party/contractorto provide working equipments/tools for the works.

42. The successful party/contractor is exclusively responsible for the safety of the workers engaged by them. The successful party/contractor shall take proper insurance to cover all probable risk, including but not limited to Employees Compensation. Any loss/damage caused to the machinery shall be the sole responsibility of the successful party/contractor. 43. The successful party/contractor shall take care to see that no damage is caused to any materials/assets inside the premises of KBPS. In case of damage to any materials, it shall be the sole responsibility of the successful party/contractor to repair or replace it at their cost. In case of any failure on the part of the successful party/contractor in this regard, KBPS shall repair or replace the same and recover the expenses from the successful party/contractor or any amount due to them.

44. The KBPS management reserves the right to cancel/terminate the contract/order without assigning any reason whatsoever and recover the damages/penalty from the successful party/contractor and to assign whole or part of the contract/order to any other party.

45. Smoking, usage of intoxicants or any other kind of indisciplinary activities are strictly prohibited inside the premises of KBPS. Violation of the same by The successful party/contractor or its employees, KBPS shall have the right to terminate the work forthwith and recover the loss or damages caused to it in this regard. KBPS shall have the right to amend the terms and conditions of this work order after intimating it to the successful party/contractor.

46. Any dispute or differences, in respect of this work order shall be referred to a sole arbitrator to be appointed by KBPS and the venue of arbitration shall be at Ernakulam. The provisions of Arbitration and Conciliation Act, 1996 as amended by amendment act 2015 will govern such proceedings.

47. All the rights to accept or reject whole or part of the tender without assigning any reason thereof is reserved by KBPS. The decision of KBPS will be final and binding on the tenderer.

48. All the rules and regulations of the Tender/bid shall be in accordance with the Stores Purchase Manual of the Government of Kerala.

Sd/- MANAGING DIRECTORPage 5 of 5 This is a digitally signed Gazette. Authenticity may be verified through https://compose.kerala.gov.in/

In the Court of The Additional Sub Judge, Kottayam Present : SMT. SONY, A. S., Additional Sub Judge (In-Charge)

Monday the 6th day of April, 2026/16th day of Chaitra, 1948.

I.A. 05/2026 in OP (Insolvency) 04/2018

Petitioner :- ADV. P. K. VINODKUMAR, Special Receiver.

Counter Petitioners :-

1. K.V. Viswanathan (Died), aged 68 years, S/o. Vasudeva Panikkar, residing at Kunnathukalathil Jino Bhavan, Thekkumgopuram, Thirunakkara Kara, Kottayam P.O., Kottayam Village, Kottayam Taluk, Kottayam District-686 001.

2. Ramani Viswanathan, aged 74 years, W/o. K.V. Viswanathan, residing at Kunnathukalathil Jino Bhavan, Thekkumgopuram, Thirunakkara Kara, Kottayam P.O., Kottayam Village, Kottayam Taluk, Kottayam District-686 001.

CP 1 Died

CP 2 By Adv. K. C. Eldho, Adv. Jijo Thomas, Adv. Mallenathan M., Adv. Anitha V. R. & Adv. Aneesh James.

This petition coming up for consideration on 6-4-2026 and court on the same day passed the following.

ORDER

Petition allowed. Produce Gazette notification and paper publication published in the leading newspaper 19-5-2026.

Pronounced in open court on this the 6th day of April, 2026.

SONY, A. S., Additional Sub Judge (In-charge).

APPENDIX:- Nil

(Id.) Additional Sub Judge.

(Sd.)

AMRITHA, T., Additional Sub Judge. For SONY, A. S., Additional Sub Judge (In-charge).

IN THE COURT OF THE HONOURABLE ADDITIONAL SUB COURT, KOTTAYAM

Insolvency Petition No. 4 of 2018

Petitioners/Debtors Respondents

1. K.V. Viswanathan NJT Finance Pvt. Limited & others Kunnathukalathil

2. Ramani Viswanathan

do.

NOTICE (FORM NO.12)

Issued under section 31 & Rule XXI of the Kerala Insolvency Act 1955.

The petitioners herein submitted the above numbered Insolvency Petition for adjudging them as Insolvents before this court on 19-6-2018. In the above case the petitioners were adjudged as Insolvents on 12-3-2026. By the order the Insolvents are directed to apply for discharge within 6 months.

The creditors are directed to submit the claim petitions in Form No. 5 of the Kerala Insolvency Rules with the supporting documents in original.

(Sd.)

Sub Judge

Kottayam, Addl. Sub Court (Insolvency Court), 4-4-2026. Kottayam.

____________________________________________________________________________________________________________________________ PUBLISHED BY THE SUPERINTENDENT OF GOVERNMENT PRESSES AT THE GOVERNMENT CENTRAL PRESS, THIRUVANANTHAPURAM, 2026This is a digitally signed Gazette. Authenticity may be verified through https://compose.kerala.gov.in/